16.04.2020

COVID-19: It’s not plain sailing for yacht owners

These are challenging and uncertain times and we wanted to provide a briefing on some of the issues yacht owners may be experiencing during the current lockdown.

Do you have a mortgage over your yacht?   

In New Zealand, we are yet to hear of any defaults being triggered by lenders to yacht owners as a result of the COVID-19 pandemic.  However, yacht owners with borrowing secured against their yachts should be aware of the possibility that some lenders might, in due course, use this as an opportunity to look at whether a default has been triggered under the material adverse change (MAC) or financial liquidity provisions of their facility agreement.  

A MAC clause covers unanticipated events which may affect a borrower’s ability to continue to service their loan or the financed asset, or the enforceability of the security. In a COVID-19 situation, a MAC default could potentially be triggered if a lender had evidence that the yacht owner would soon be unable to repay and service their loan and/or maintain the yacht in accordance with the loan covenants, either because the charter income has significantly declined or of a material change in the cash flow of the borrower. This could also trigger the financial liquidity provisions and it may require the borrower to make further deposits with the lender to increase it’s security.

We are in a constantly evolving situation. At present, banks are working with their customers to support them through these uncertain times and we would expect this to continue, for the short term at least; however, this may take a different turn if payment defaults increase.  From our experience, it’s better to be proactive, if your circumstances have changed, and start the dialogue with your lender now.

Is your yacht currently undergoing a refit

Check your contract, does it have a force majeure clause?  There is a possibility that COVID-19 would be deemed a force majeure event under many refit and repair contracts. It is the yard’s responsibility to demonstrate the impact COVID-19 has had on each project, and to comply with all contractual notice obligations.  Correctly giving notice is the first step. The yard will need to quantify the loss for each project and to show its attempts to mitigate any losses or delays.  The best thing to do in this situation is to keep real-time, daily records of how each project is affected.  Disputes are likely to arise only nearer delivery/re-delivery and having contemporaneous records of the delays caused and the steps taken to mitigate them will be invaluable to support any claim for permissible delay.  Yards should be making every effort to keep their clients regularly updated, this helps to manage client expectations and will be more relevant as New Zealand moves to lower alert levels and non-essential work can restart.

Are you selling or buying a yacht?

If you are buying or selling a large yacht (24 metres or more), you may be using the internationally recognised MYBA form of sale agreement or a similar document.  This agreement has a force majeure clause which will enable the contract to be extended for delays caused by “government act or regulation“.  Other contracts are unlikely to have these similar provisions and disputes are likely to arise as buyers and sellers are unable to fulfil their contractual obligations, especially as inspections and physical deliveries are unable to take place.  If in doubt, check your contract.  We would recommend negotiating an extension to the agreement.

If you have any questions about COVID-19 and the issues facing yacht owners, please get in touch with our marine team or your usual contact at Hesketh Henry.

Disclaimer:  The information contained in this article is current at the date of publishing and is of a general nature.  It should be used as a guide only and not as a substitute for obtaining legal advice.  Specific legal advice should be sought where required.

 

 

 

 

Do you need expert legal advice?
Contact the expert team at Hesketh Henry.
Kerry
Media contact - Kerry Browne
Please contact Kerry with any media enquiries and with any questions related to marketing or sponsorships on +64 9 375 8747 or via email.

Related Articles / Insights & Opinion

Privacy Commissioner to consult on Privacy Rules for Biometric Information
With the increasing use of facial recognition technology (FRT), retinal scans, and voice recognition by an array of different agencies, privacy concerns about its collection and use are set to be form...
24.11.2023 Posted in Business Advice
Fern forest NZ
Bioenergy in New Zealand: Fuels for the Future?
The energy transition from combustion fuels to low carbon alternatives is viewed as critical in the race to cut global CO2 emissions and reach climate targets.  We look at some of the opportunities p...
14.11.2023 Posted in Business Advice & Climate Change & Forestry
Will Wide BW
A well drafted will is a craft
The New Zealand do-it-yourself “DIY” attitude and way of life is not limited to home improvements, but sometimes also extends to wills.  Recently we had a DIY $5.99 fill in the blanks will acros...
07.11.2023 Posted in Private Wealth
rsz large pillars
Health and Safety: The Consequences of Dishonesty
Siddhartha Gautama said that lies are like huge, gaudy vessels, the rafters of which are rotten and worm-eaten, and that those who embark in them are fated to be shipwrecked.  Two remarkable health a...
03.11.2023 Posted in Employment & Health & Safety
Properly sequencing your Construction Adjudications: Henry Construction Projects Ltd v Alu-Fix (UK) Ltd
According to the UK’s Technology and Construction Court (TCC) (in Henry Construction Projects Ltd v Alu-Fix (UK) Ltd [2023] EWHC 2010) valid payment claims must be paid before the underlying merits ...
30.10.2023 Posted in Construction & Disputes
Key change to rules on distribution of surplus assets under the new Incorporated Societies Act 2022
On 5 October 2023, the new Incorporated Societies Act 2022 (2022 Act) came fully into force, replacing the Incorporated Societies Act 1908 (1908 Act). One of the key requirements under the 2022 Act is...
18.10.2023 Posted in Business Advice
Construction Framework Wide BW
Major milestone passed – NZS3910:2023 expected in time to fill Christmas stockings
As the most widely adopted standard form construction contract in NZ, NZS 3910 was more than ready for updated conditions given the changes in the industry since its last review in 2013.  After almos...
09.10.2023 Posted in Construction
SEND AN ENQUIRY
Send us an enquiry

For expert legal advice, please complete the form below or call us on (09) 375 8700.